Insights

On February 6, 2025, Crowell & Moring presented a webinar, "The New Normal: What U.S. Government Contractors and Grant Recipients Need to Know About Terminations, Stop Work Orders, Tariffs, and the Path Forward in 2025."  In this webinar (available here), Crowell & Moring lawyers specializing in U.S. government contracts and grants addressed:

In MVL USA, Inc. et al. v. United States, the United States Court of Federal Claims (“COFC”) held that the provisions of FAR 22.505, 52.222-33 and 52.222-34 (collectively, the “PLA mandate”), which required the use of project labor agreements (“PLAs”) on large-scale federal construction projects valued above or at a certain threshold, violated the Competition in Contracting Act (“CICA”). As we previously reported here, former-President Biden issued Executive Order 14063 in February 2022, instructing federal agencies to require construction contractors and subcontractors on projects valued at $35 million or more to “agree, for that project, to negotiate or become a party to” a PLA. A few months later, the FAR Council promulgated a final rule implementing the executive order in FAR 22.505, 52.222-33 and 52.222-34. 

In a big change for defense contractors, Congress has amended 10 U.S.C. § 3372 to make clear that a Department of Defense (DoD) contracting officer’s unilateral definitization of an undefinitized contract action is directly appealable to the Armed Services Board of Contract Appeals (ASBCA) or the Court of Federal Claims. Congress’s change (made under Section 803 of the Servicemember Quality of Life Improvement and National Defense Authorization Act (NDAA) for Fiscal Year (FY) 2025) (we report on the FY 2025 NDAA here) is contrary to recent ASBCA and Federal Circuit decisions.

On October 31, 2024, the Armed Services Board of Contract Appeals (ASBCA or Board) published its FY 2024 Report of Transactions and Proceedings, which provides statistics regarding the “adjudication of appeals, petitions for contracting officer final decisions, applications for fees and costs under the Equal Access to Justice Act, and other matters” of the Army, Navy, Air Force, Corps of Engineers, Defense Logistics Agency, Defense Contract Management Agency, Central Intelligence Agency, National Aeronautics and Space Administration, or the Washington Metropolitan Area Transit Authority. 

The Civilian Board of Contract Appeals (CBCA or Board) recently published its Annual Report for FY 2024, providing statistics regarding the adjudication of appeals between contractors and civilian agencies. This year, the civilian agencies with the highest number of docketed claims at the Board were the Department of Veterans Affairs, the General Services Administration, the Department of State, the Department of Homeland Security, and the Department of Agriculture. These agencies accounted for 126, or 76%, of the 165 Contract Disputes Act (CDA) appeals docketed at the Board. 

On December 17, 2024, the Civilian Board of Contract Appeals (Board) announced its plan to launch a new Electronic Docketing System (EDS).  Once implemented, the Board will require use of the new EDS for most submissions. 

In Fortis Industries, Inc., CBCA 7967 (Sept. 18, 2024), the Civilian Board of Contract Appeals (CBCA) denied in part the government’s motion for partial summary judgment on the issue of whether the contractor released its claims by signing a modification terminating the contract for convenience. During contract performance, the General Services Administration (GSA) imposed monthly deductions to contract payments as a response to certain performance issues. GSA later proposed to terminate the contract for convenience and sent a contract modification stating that all obligations under the contract were concluded except payment for work performed in June 2022. The contractor signed the modification but stated in its transmittal email that it was owed payment for services in May 2022 as well. 

In Chugach Federal Solutions, Inc., ASBCA Nos. 62712, et al., the Armed Services Board of Contract Appeals held that a contractor could recover its costs for having to quarantine personnel in accordance with government-imposed COVID safety requirements, because the underlying contract contemplated that the contractor would be compensated for complying with any changes to health and safety requirements.

The federal government’s response to Hurricanes Helene and Milton will increase its reliance upon government contractor support to perform critical tasks in the coming months.  The Federal Emergency Management Agency and other federal, state, and local agencies charged with disaster response and recovery will look to contractors to provide everything from logistics to housing, construction, and security services.  National disaster contracting provides contractors with immediate opportunities to assist in the recovery effort, but given the time sensitivity, evolving customer needs, and critical nature of the work, contractors must be prepared to: (i) perform under tight deadlines and high scrutiny; (ii) seek clarity with respect to the scope of work they are asked to perform; (iii) properly manage contract and change order documentation; and (iv) maintain contract files for subsequent audits and other inquiries which can take place years after the recovery effort has ended.  One of the most common contract risks associated with disaster response efforts is the inevitable “scope creep” as contractors encounter ever-changing events on the ground, which puts an emphasis on record keeping and timely communications with government customers, to ensure payment for work performed.

At midnight on October 1, 2024, the International Longshoremen’s Association launched a labor strike that effectively shut down all ports from Maine to Texas after being unable to reach agreement on terms for a new labor contract with the United States Maritime Alliance.  This strike may impact virtually all industries that rely on maritime shipping, either directly or indirectly. 

In Konecranes Nuclear Equip. Servs. LLC, ASBCA, Nos. 62797, 62827 (May 7, 2024), the Armed Services Board of Contract Appeals (Board) awarded approximately $4.9 million in delay-related breach damages to Konecranes Nuclear Equipment Services (Konecranes) due to the Navy’s breach of its implied duty to not interfere on a commercial-item contract for the provision of 25-ton general purpose portal cranes.

In Portland Mint v. United States, Case No. 22-2154, the Court of Appeals for the Federal Circuit reinstated the Portland Mint’s claim that the government breached an implied-in-fact contract to pay the Portland Mint for coins tendered under the government’s Mutilated Coin Redemption Program.  The Court’s decision is a reminder of the jurisdictional importance in pleading a contract as implied-in-fact rather than implied-in-law. 

In Lockheed Martin Aeronautics Company, ASBCA No. 62209 (a C&M case), the Armed Services Board of Contract Appeals (Board) awarded $131,888,860 in damages plus applicable interest in connection with Lockheed Martin’s claim for the cumulative disruptive impacts it experienced in performing over and above work on the C-5 Reliability Enhancement and Re-Engining Program.  The underlying contract related to the modernization of a fleet of C-5 Galaxy Aircraft, which is the largest U.S. military transport plane and has provided heavy intercontinental strategic airlift capabilities since the 1970s.  The Board sustained the appeal after finding that Lockheed Martin had met its burden of proof on entitlement and quantum, using the measured-mile methodology, which compares an affected period of performance with an unaffected period.  This case is a prime example of marshalling fact and expert witness testimony, and documentary evidence, to demonstrate the impacts of cumulative disruption on performance to justify causation and damages.

In the Crowell & Moring case Parsons Government Services, Inc. v. Department of Energy, CBCA 7822, the Civilian Board of Contract Appeals (Board) denied the government’s motion to dismiss concerning Parsons’ claim for additional incentive fee in connection with its performance operating a salt waste processing facility at DOE’s Savannah River Site.  The underlying contract relates to a first-of-its-kind facility to treat and reduce liquid radioactivity in nuclear waste.  In its decision, the Board rejected the government’s motion to dismiss, holding that Parsons had pled sufficient facts to support its claims regarding superior knowledge, impracticability of performance, and breach of the duty of good faith and fair dealing.

In MLU Services, Inc. v. Department of Homeland Security, CBCA No. 8002, the Civilian Board of Contract Appeals (Board) denied a Federal Emergency Management Agency (FEMA) motion to dismiss for failure to prosecute, which the agency filed just four days after MLU failed to timely submit one of its initial pleadings.

In Aviation Training Consulting, LLC, ASBCA No. 63634 (Jan. 11, 2024), the Armed Services Board of Contract Appeals (ASBCA) confirmed that a contractor’s properly asserted claim for relief under Section 3610 of the Coronavirus Aid, Relief, and Economic Security (CARES) Act is a claim under the Contract Disputes Act (CDA) and denied the Air Force’s motion to dismiss for lack of jurisdiction.

The Civilian Board of Contract Appeals (CBCA) recently published its Annual Report for FY 2023, providing statistics regarding the adjudication of appeals between contractors and civilian agencies such as the Department of State, the Department of Veterans Affairs, the General Services Administration, the Department of Transportation, the Department of Agriculture, the Department of the Interior, and the Central Intelligence Agency. According to this year’s report, contractors prevailed in 45% of the appeals decided on the merits, which is much higher than the 21% success rate in 2022. The report also shows that the CBCA’s alternative dispute resolution (ADR) program remains successful—resolving 70% of appeals for which the parties completed ADR. All of this came in the context of a substantial jump in the number of appeals, with 246 new appeals docketed in 2023 compared to 177 in 2022 and 185 in 2021. Click here to view the full CBCA report.

In Flatland Realty, LLC, ASBCA No. 63409, the Armed Services Board of Contract Appeals (Board) granted an appeal seeking damages, plus interest, from an improper termination for default.  In an uncommon result, the Board awarded lost profit expectancy damages because the government had improperly terminated the contract, which did not incorporate a termination for convenience clause.

On November 1, 2023, the Armed Services Board of Contract Appeals (ASBCA) published its FY 2023 Report of Transactions and Proceedings, which provides statistics regarding the adjudication of appeals between contractors and the Army, Navy, Air Force, Corps of Engineers, Central Intelligence Agency, National Aeronautics and Space Administration, Defense Logistics Agency, Defense Contract Management Agency, other Defense agencies, Non-Appropriated Fund Instrumentalities, and the Washington Metropolitan Area Transit Authority.

In ECC Int’l Constructors Inc. v. Army, No. 2021-2323 (Fed. Cir. Aug. 22, 2023), the Court of Appeals for the Federal Circuit overturned longstanding precedent by holding that the requirement to state a “sum certain” in a claim submitted under the Contract Disputes Act (CDA) is not a jurisdictional requirement.  The Court based its decision on recent Supreme Court guidance to “treat a procedural requirement as jurisdictional only if Congress ‘clearly states’ that it is.”  The Court parsed the CDA and found that Congress never used the words “sum certain,” evidencing that Congress did not intend the requirement to be jurisdictional.  This is important because jurisdictional requirements can be raised at any time—even years after the claim was filed and a full hearing on the merits was held—and result in dismissal of the case.  The Court explained that the “sum certain” is “nonetheless a mandatory rule that claimants must follow.”